The Department may determine losses sustained by contractors engaged on State highway projects incident to the suspension of work on such project by a court injunction order and may compensate such contractors for the amounts of the losses so determined. But this authority shall be limited to the payment of actual and unavoidable losses, not to include anticipated profits. Should any contractor be dissatisfied with the determination of his losses by the Department, such contractor may bring suit against the Department in the court of common pleas for the determination of the reasonableness of the amount of the award for such losses.
HISTORY: 1962 Code Section 33-227; 1952 Code Section 33-227; 1951 (47) 457.
Copyright ©2024 LegalFix. All rights reserved. LegalFix is not a law firm, is not licensed to practice law, and does not provide legal advice, services, or representation. The information on this website is an overview of the legal insurance products you can purchase—or that may be provided by your employer as an employee benefit or by your credit union or other membership group as a membership benefit.
LegalFix provides its members with access to legal services through a network of provider law firms. LegalFix, its corporate entity, and its officers, directors, employees, agents, and contractors do not provide legal advice, services, or representation—directly or indirectly.
The articles and information on the site are not legal advice and should not be relied upon—they are for information purposes only. You should become a LegalFix member to get legal services from one of our provider law firms.
You should not disclose confidential or potentially incriminating information to LegalFix—you should only communicate such information to your provider law firm.
The benefits and legal services described in the LegalFix legal plans are not always available in all states or with all plans. See the legal plan Benefit Overview and the more comprehensive legal plan contract during checkout for coverage details in your state.
Use of this website, the purchase of legal insurance products, and access to the LegalFix network of provider law firms are subject to the LegalFix Terms of Service and Privacy Policy.
